Following terms and conditions apply for any and all businesses. Contrary or varying conditions of Purchaser (or Seller) are invalid unless explicitly confirmed by ANKER-TEC GmbH (hereinafter referred to as “ANKER-TEC”) in writing.
Quotations by ANKER-TEC are non-binding. Any purchase order is subject to ANKER-TEC’s written confirmation. All technical references to weights, dimensions and specifications are subject to commercially acceptable tolerances and changes, unless explicitly declared as binding.
Unless otherwise agreed, prices are calculated basis ex works Bunsenstrasse 3, 24145 Kiel, Germany, Incoterms 2010 FCA conditions.
Prices are based on cost of materials and salaries at the time of ANKER-TEC’s confirmation of a purchase order. In case of delays exceeding 3 months outside the control and responsibility of ANKER-TEC, ANKER-TEC may adjust prices reflecting actual price increases.
All prices are net of Value Added Tax (VAT) which to be added in accordance with governing laws.
Unless otherwise agreed, payments are due and earned against invoice as follows:
a) Machine sales incl. accessories, installation and commissioning – without any deductions:
b) Spare Parts & Upgrades, parts and wearing parts: Irrespective of receiving the merchandise within 30 days net from date of invoice; within 2 weeks a 2 % cash discount can be deducted.
c) For goods purchased by ANKER-TEC, payments within 30 days net from date of invoice or within 2 weeks less 2% cash discount.
d) Engineering and other services: Payment is due within 8 days net from date of invoice without any deductions.
All payments to be made by bank transfer.
If payments are deferred or paid later than agreed, Purchaser is to pay interest in respect of the period of delay in the amount of at least 8 % points above the current basic interest rate of the European Central Bank. Giving notice of default is not required.
The purchaser only has a right of retention or compensation in the case of counter-claims, if counter-claims are uncontested or settled by a final court verdict.
The outstanding claim becomes due, if Purchaser does not fulfill his duty to pay or becomes insolvent or if ANKER-TEC obtains information about an economic deterioration of Purchaser that may jeopardize the purchase price.
If the outstanding claim is not paid immediately, Purchaser loses the right to use of the object of delivery. ANKER-TEC is entitled to take back the object of delivery or to cancel the agreement without renouncing his claim until full payment has been made.
If Purchaser has caused the cancellation of the agreement, ANKER-TEC is entitled to claim for compensation including lost profits. Any repossession of the object of delivery is at the expense of the Purchaser.
Time of delivery, installation and commissioning is set after a purchase contract is signed or after receipt of a purchase order, provided all technical questions are cleared and all documents, such as clearance certificates, required to be presented by Purchaser have been received as well as an agreed down payment.
The deadline of delivery is met once the object of delivery has been shipped from the factory or when readiness for the shipment has been announced. In the case that an Pre-Acceptance Protocol was agreed, then the time of the execution of the Pre-Acceptance Protocol is decisive, at least when readiness for carrying out the acceptance procedure was notified. This does not apply if refusal of the goods is justified.
In the case that there is a delay of shipping caused by Purchaser of more than a month after announcing readiness for shipment, then all costs of storage will be calculated as follows: If stored at the factory of ANKER-TEC, storage charges amount to 0,25 % of the purchase price per month/pro rata. ANKER-TEC reserves the right to present evidence about higher or lower storage costs. ANKER-TEC is entitled to dispose of the object of delivery otherwise, provided ANKER-TEC has set an appropriate deadline before. ANKER-TEC may claim further damages caused by such delay.
All risks pass to the Purchaser in accordance with Incoterms 2010 FCA at Bunsenstrasse 3, Kiel, or Incoterms 2010 DAP at destination, whatever applicable.
If Purchaser has caused delay of shipment, the risk passes as of the declaration of readiness for shipment and its communication to Purchaser. However, ANKER-TEC is obliged to enter an appropriate insurance-contract at the request and at the costs of the Purchaser.
Unless otherwise agreed shipments on the basis of Incoterms 2010 DAP will be insured at the expense of ANKER-TEC against theft, breakage, damage of transport, damages caused by fire or water leaks as well as other insurable risks.
Partial shipments are permitted.
ANKER-TEC retains title and the extended reservation of title to the goods delivered pending performance of all of ANKER-TEC’s claims against Purchaser including costs and interest.
The same procedure applies for the extended reservation of title. A foreign Purchaser is obliged to respect as close as possible according to the local law the extended reservation of title. A foreign Purchaser is obliged to agree this subject with ANKER-TEC. In the event of any transformation of the object of delivery with other objects, reservation of title remains fully in force.
Purchaser is obliged to take special care of the object of delivery until property passes. ANKER-TEC is entitled to insure the object of delivery at the expense of Purchaser against theft, breakage, fire, water leaks and other damages unless Purchaser has given documented evidence that he has entered an insurance contract himself. Purchaser has to pay for necessary service and repair works at his own costs in due time.
Purchaser is not entitled to pledging, leasing, renting out, selling to third parties or assigning the goods delivered as collateral. In case of pledging, confiscation or other dispositions by third parties, ANKER-TEC has to be informed immediately. Purchaser is obliged to reimburse justified in or out of court interventions, such as filing legal action in accordance with § 771 of the Code of Civil Procedure (ZPO).
If Purchaser is in breach of contract, in particular in the case of a significant delay of payments, ANKER-TEC may withdraw – after a written notice – the goods as a security.
If Purchaser sells the goods delivered in violation of the agreement, Purchaser now already assigns to ANKER-TEC all claims arising therefrom (including VAT). ANKER-TEC accepts the assignment. ANKER-TEC is entitled to collect the assigned claim against the third party. ANKER-TEC is also entitled to raise reservation of title to the goods delivered.
Purchaser has to notify ANKER-TEC about all details of the assignment by providing all necessary documentation and notifying the third party of the assignment. Any change or transformation of the object of delivery by Purchaser is carried out on behalf of ANKER-TEC.
ANKER-TEC will be joint owner calculated as quota of the sales price compared to the value of the other material added at that time. Any connection of the object of delivery with other objects not owned by Purchaser also creates a joint ownership with the corresponding value of the object of delivery with the third owner at that time.
If the object of delivery is connected with real property, Purchaser assigns to ANKER-TEC that claim arising for Purchaser against a third party as a result of the connection of the goods delivered with the real property. That claim includes VAT. ANKER-TEC hereby accepts the assignment.
Retention of title and extended reservation of title to the goods are agreed under the condition that full payment transfers property and all assigned claims automatically to the Purchaser.
ANKER-TEC may cancel the agreement and may immediately request the return of the object of delivery in case of an insolvency procedure against Purchaser.
For any defects of delivery that include the non-fulfillment of explicitly guaranteed characteristics of the object of delivery, ANKER-TEC is responsible as follows by the means of excluding further claims:
Physical defects of the objects of delivery:
All parts have to be repaired or renewed at the discretion of ANKER-TEC if the object of delivery cannot be used or if usage is substantially impaired. This requires that a defect comes up within twelve months of use of the object of delivery. Examples of such defects are a faulty construction of the object, materials of bad quality or an imperfection of usability. Such defects have to be communicated to ANKER-TEC in writing immediately. The parts in issue have to be sent to ANKER-TEC immediately, if requested.
Purchaser has to grant sufficient time and opportunity for ANKER-TEC to carry out all repairs and replacements deemed necessary by ANKER-TEC. Otherwise ANKER-TEC is released from liability and its consequences.
ANKER-TEC bears all direct costs for repair or replacement, provided that all the Purchaser’s claims prove to be fully justified and were raised in time.
In the case ANKER-TEC ignores an appropriate deadline for repair or replacement, Purchaser is entitled to cancel the agreement in accordance with the law. In the case there is a defect that cannot be considered substantial, Purchaser is limited to claim a reduction of the price only. The reduction of the purchase price remains excluded otherwise.
Warranty is excluded for wearing parts and following cases: Inappropriate use, inappropriate services when setting up the object of delivery by the Purchaser or third parties, natural wear and tear, incorrect or negligent use of the object, incorrect services, use of inappropriate lubricants, use of inappropriate material and/or non-original parts when exchanging certain parts of the object of delivery, inappropriate storage rooms, chemical, electrochemical or electrical influences – as long as such circumstances do not fall under the control of ANKER-TEC. ANKER-TEC is not liable as far as corrosion of the used materials is concerned. Corrosive influences can lead to considerable changes during time of usage.
In the case Purchaser or third parties carry out any changes or repairs without prior permission of ANKER-TEC then all liability for all consequences of such steps is suspended. This also applies for the usage of spare parts and consumables not delivered by ANKER-TEC, because the object of delivery needs original spare parts in order to guarantee its functionality.
For repairs without legal obligations warranty only applies, if same has been agreed upon in writing. Same applies for the compliance with technical and legal regulations outside Germany.
Legal Infirmity:
In the case that the use of the object of delivery violates any industrial property rights or intellectual property, ANKER-TEC will as a matter of principle and at his expense make sure that Purchaser will be reinstated in his rights of usage. ANKER-TEC has the option to change the object of delivery in an appropriate manner designed to avoid further violations of industrial property rights. Outside the territory of the Federal Republic of Germany such an obligation requires an agreement in writing. Purchaser may cancel the agreement if reinstatement of his rights is impossible due to unreasonable economic burdens or reinstatement cannot be carried out within reasonable time. ANKER-TEC is also entitled to cancel the agreement under the same conditions. Moreover ANKER-TEC will indemnify Purchaser of uncontested or legally valid industrial property rights claims from third parties.
All obligations according to cipher 8 are only valid if:
– Purchaser informs ANKER-TEC about the asserted violation of law immediately;
– Purchaser supports ANKER-TEC adequately when defending such claims;
– ANKER-TEC’s rights of defense including agreements in court and out of court are reserved;
– the legal infirmity was not caused by an instruction of Purchaser;
– the violation of law was not caused by any changes to the object of delivery by Purchaser or where the use of the object opposes the agreement.
If the object of delivery has not been used by Purchaser properly because ANKER-TEC violated duties of information or other contractual secondary duties, in such a case § 8 and § 9.2 apply accordingly. Further claims are excluded.
ANKER-TEC, irrespective on what legal grounds, is liable for damages occurring other than to the object of delivery itself, only in the following circumstances:
a) when acting with intent;
b) in case of negligence unless slight negligence, or gross negligence in case of employees without being at the managing level;
c) when at fault causing death, bodily injury, impairment of health;
d) undisclosed defects with intent to deceive or a guarantee that certain defects will not occur;
e) defects of the object of delivery that prompt liability claims according to the compulsory Rules of the Product Liability Act. In case of claims according to Product Liability Act ANKER-TEC is entitled to assign his claims of the insurance company, if legally permitted. If such claims are assigned and accepted on the basis of the Product Liability Act, all claims are thereby settled.
f) in the event of a breach of a so-called cardinal-obligation, that is a breach of contractual duties that are an essential requirement to the execution of the contract and on which the Purchaser may reasonably rely on in which case, also for gross negligence of employees not being on the manager level or for slight negligence; in the last case, claims are limited to damages typical and foreseeable for such contracts.
Within the scope of an insurance contract for property damage of ANKER-TEC the exemption clauses do not apply.
All other claims, consequential claims in particular, are excluded.
Purchaser is entitled to cancel the agreement without notice, if the delivery of the object becomes impossible before passing the risk. Purchaser may also cancel the agreement, if the execution of the order of confirmation becomes partially impossible and if Purchaser has a justified interest to deny a partial delivery. If this is not the case, the Purchaser has to pay for a partial delivery part of the contractual price. The same applies if ANKER-TEC is unable to deliver, see reference in § 9.2. If the impossibility to deliver occurs during a delay of Purchaser or Purchaser is solely or largely responsible for such circumstances, Purchaser remains obligated to pay.
If Purchaser sets an appropriate deadline and the deadline is not respected, Purchaser is authorized to cancel the agreement in accordance with the law. All other claims based on delay are regulated exclusively according to § 9.2.
The agreement has to be adjusted in good faith if foreseeable events acc. to § 5.3 change the economic significance or its contents or have a significant influence on ANKER-TEC. In the case that such an adjustment would be unreasonable economically, then ANKER-TEC is entitled to cancel the agreement. If ANKER-TEC wants to invoke his right of cancellation of the agreement, he is obliged to inform Purchaser about the scope of this event immediately, even then if a prolongation of the period of delivery is agreed.
In the event of delays and cancellations of Purchaser, ANKER-TEC is entitled to be kept in the same position as if the agreement had been carried out according to the agreement. Only damage claims that are specified and can be foreseen and calculated in advance are reimbursable. Loss of profit, lawyer’s and court costs are part of such concrete and foreseeable claims for reimbursement.
All claims of Purchaser – no matter on what legal grounds – are statute-barred within 12 months unless there is an opposing special compulsory law. Visible defects have to be communicated in writing to ANKER-TEC within 14 days of receipt in order to avoid the loss of remedies. In case of repair or replacement the claims are statute-barred after six months. This period cannot end earlier than the original period on the statute of limitations.
In the event the object of delivery includes software, Purchaser obtains a non-exclusive license to use the software. It may be used on specifically designed hardware. Multiple-use of the software requires written permission. Software delivered to Purchaser cannot be changed without written permission.
Installation works have to be remunerated, unless otherwise agreed. In the case there is a delay of the assembly or bringing the machine into service without being the fault of ANKER-TEC, Purchaser has to reimburse the expenses for waiting-time and further necessary travels, accommodation and associated costs.
Following a Pre-Acceptance Protocol at ANKER-TEC’s works prior to shipment, a Protocol of Acceptance has to be issued and signed by both parties immediately after ANKER-TEC announcing completion of installation and commissioning at Purchaser’s site. Purchaser cannot refuse his signature if there is only a defect that cannot be considered substantial and Purchaser is in spite of § 8 obliged to accept the object of delivery.
All replaced parts become property of ANKER-TEC.
ANKER-TEC reserves the right of property and copyrights on all designs, plans, instruction books, technical descriptions, costs, estimates and other physical, intangible or electronic information. Such documents cannot be copied nor used for non-contractual purposes without written permission. Access cannot be given to third parties (not even on the basis of a request). The documents cannot be published. The same applies for any trade secrets, know-how or secrets of any production process, that has been made known to the Purchaser or becomes known to him otherwise.
Purchaser acknowledges all patent rights, copyrights and other industrial property rights of ANKER-TEC including the software, irrespective whether such rights are governed by German or foreign law. The protection of the software extends also to the protection of copies of the software. No sublicense can be granted to third parties without written permission of ANKER-TEC.
Any reproduction of machines, installations, components or parts thereof as well as software is not permitted. Any violation will be pursued by ANKER-TEC without exception on a worldwide basis by exploiting all legal remedies of the Civil and Criminal Law. If permitted by law, not only the actual damage, but also punitive damages will be pursued.
Reverse engineering, i.e. the analysis of the structure and the function of products delivered by ANKER-TEC is not permitted.
The factory of ANKER-TEC is place of the performance for delivery and services.
All written communications to ANKER-TEC required by these General Terms of Business have to be sent directly to the headquarters of ANKER-TEC at Bunsenstrasse 3 in D-24145 Kiel. Every additional agreement – orally or on the telephone – requires confirmation in writing by ANKER-TEC. Informations, changes, etc. communicated by ANKER-TEC in writing are considered to be accepted by the Buyer if he does not object in writing within 3 working days.
In the event of any dispute arising from the contractual relationships between the parties, the Courts of Kiel, Germany, shall have jurisdiction and venue. ANKER-TEC does however also have the rights to bring an action against the Purchaser at the Courts with jurisdiction at the place of business of the Purchaser.
These General Terms of Business and the entire legal relationship between ANKER-TEC and Purchaser shall be exclusively construed in accordance with the Laws of the Federal Republic of Germany including the application of the UN-Convention on the International Sale of Goods (CISG).
Should any provision in these General Terms and Conditions of Sale and Delivery or any provision within the framework of other contracts be or become invalid, this shall not affect the validity of all other provisions or contractual agreement. The parties are obliged in such a case to replace the invalid clause by a valid clause which should be in economic terms as close as legally possible as the previous regulation. The same applies for gaps.
Any alterations and amendments require written confirmation by ANKER-TEC to be effective.
Kiel (Germany)
The following Terms and Conditions of Service and Supply (hereinafter “Terms”) apply exclusively to all supply offers made by ANKER-TEC, to all supply contracts concluded by ANKER-TEC and to all supplies and services of ANKER-TEC. Any general terms and conditions of the Customer contrary to or further-reaching than the Terms apply only with positive confirmation from ANKER-TEC. These Terms also apply to all future supply agreements with the Customer.
Offers made by ANKER-TEC are non-binding. Conclusion of contract requires written form. A contract comes, however, about at the latest upon commencement of transportation of the equipment to the Customer. Copies provided to the Customer are not valid as order confirmation.
No oral side agreements have been made. Oral agreements made by commercial agents or other field staff of ANKER-TEC are only valid if confirmed in writing by ANKER-TEC.
Specifications concerning measurements, weights and performance and figures and drawings are binding only if this has been expressly agreed. The Customer is obliged to inform ANKER-TEC of any obvious errors as well as typographical or computational errors in order that the corresponding information may be rectified or updated. The same applies in the event of missing documents.
After conclusion of contract – but only up to preliminary acceptance – ANKER-TEC is within the scope of what is reasonably acceptable for the Customer entitled to amend contractual terms, notably with regard to design, implementation, characteristics and quality, should this appear necessary to ANKER-TEC for operational reasons. In such a case, ANKER-TEC is obliged and entitled to make a reasonable adjustment in the remuneration agreed with the Customer, notably with respect to higher or lower costs, and to adjust the delivery accordingly.
The equipment supplied only fulfills the standards and codes expressly mentioned by ANKER-TEC. The Customer is responsible for ensuring that the equipment satisfies all regulations, in particular safety regulations, valid at the place of installation or use.
The Customer has no claim to be provided with drawings, in particular design and work drawings. ANKER-TEC reserves title and copyright in cost estimates, offers, drawings and other documents. Such documents must not be made accessible to third parties and, in particular, should the contract not come about, must be returned on request to ANKER-TEC without undue delay with a declaration that no copies were made thereof. Should the Customer come into possession of the aforementioned drawings, he is prohibited from using them in any way, in particular for the purpose of imitation (even if said drawings are not protected under patent law), from forwarding the drawings and from allowing third parties to inspect the drawings. The Customer is liable for any utilization of documents having come into his possession in breach of the above.
The prices of ANKER-TEC are exclusive VAT. During assembly the Customer has at its own expense to provide the assembly staff of ANKER-TEC with all necessary support and facilities.
If a delivery period exceeding two months is agreed, ANKER-TEC is entitled to charge the Customer correspondingly higher prices for cost increases incurred in the interim for procurement, production, delivery, assembly or otherwise, including those due to changes in legislation. Upon the Customer’s request ANKER-TEC shall furnish the Customer with evidence of such cost increases.
In the case of payment default by the Customer, ANKER-TEC is entitled to withhold further supplies and services and to refuse any discounts granted on other due payments.
In the event that ANKER-TEC becomes aware of circumstances capable of casting doubt on the Customer’s creditworthiness, and which have occurred only after conclusion of contract or which ANKER-TEC has become aware of only after conclusion of contract through no fault of its own, ANKER-TEC is entitled to demand immediate payment of all residual debt. This applies in particular in the event of a cheque or other payment paper not being cleared by an instructed credit institution and in the event of suspension of payment by the Customer. In such cases, ANKER-TEC is moreover entitled to demand advance payments or security. The exercise of this right does not affect the statutory rights of ANKER-TEC.
ANKER-TEC is entitled to perform partial supplies and partial services at all times.
The Customer is obliged to accept the services performed by ANKER-TEC. To the extent that ANKER-TEC performs partial services, the Customer is bound to corresponding partial acceptance. Each acceptance is recorded in a report to be signed by both Parties.
Prior to transportation of the equipment to the Customer, preliminary acceptance will be performed at ANKER-TEC. The preliminary acceptance will be recorded in a report to be signed by both Parties. After preliminary acceptance, the Customer cannot assert any claim for defects already recognisable on preliminary acceptance. The Customer shall be informed of the date of the preliminary acceptance in writing three weeks in advance. If the Customer does not send a delegate to attend the preliminary acceptance, ANKER-TEC is entitled to perform the preliminary acceptance without the Customer with the aid of an expert. The expert exercises the rights of the Customer and the Customer bears the costs for the same.
Delivery dates and periods are only binding if expressly agreed as binding. The delivery period commences upon conclusion of contract. If any modifications are agreed with respect to the execution of the purchase object prior to delivery, the delivery period is interrupted thereby. ANKER-TEC in this case is entitled to fix a new delivery period. If ANKER-TEC does not exercise this right, the delivery period commences all over again upon agreement of the modified execution.
Delivery periods refer to the delivery of the components to the Customer excluding assembly, and thus not to completion of the installation.
If the Customer has made a call order, he is obliged to call off the equipment within 12 months at the latest (from the date of the order).
ANKER-TEC is entitled to exceed non-binding delivery dates by up to 3 weeks. The Customer is only entitled to set ANKER-TEC a reasonable grace period after expiry of these 3 weeks.
The supplies and services must be examined immediately after receipt as to whether they are proper and correct. Any apparent defects or complaints must be reported by the Customer in writing and without undue delay. Any other defects must be reported after being discovered in writing and without undue delay. If such a notice of defect is not submitted, the supply and/or service is deemed to have been approved in view of the defect. The notice of defect must give a precise description of the defect.
ANKER-TEC is not responsible for ongoing operational disruptions which cause delays in delivery and performance or make performance significantly more difficult or impossible for ANKER-TEC and which are attributable to force majeure, strikes, lock-outs, official orders or a shortage of raw materials – also if these arise at suppliers of ANKER-TEC or their sub-suppliers – even where binding periods and deadlines have been agreed. In such cases, ANKER-TEC is entitled to postpone the supply or service by the duration of the hindrance plus a reasonable start-up time or to adjust the Contract accordingly. ANKER-TEC may invoke the aforementioned circumstances only if it has notified the Customer of the same without undue delay. If an operational disruption, as described above, lasts longer than three months, both ANKER-TEC and the Customer may rescind the contract.
The statutory provisions apply to transfer of risk.
EEW Maschinenbau GmbH reserves title in the delivery items until fulfillment of all current and future claims arising from the business relationship (including all claims from current account balances).
The Customer is obliged to take out adequate insurance cover for the delivery items for as long as they remain the property of EEW Maschinenbau GmbH. EEW Maschinenbau GmbH must be informed without undue delay about any attachment or other court orders relating to delivery items which are still property of EEW Maschinenbau GmbH. The Customer bears the costs of legal action necessary to enforce the rights of EEW Maschinenbau GmbH arising from title in the delivery.
The customer is prohibited from removing, altering or garbling any marks of EEW, such as name tags or logos, on the machine or the machine parts.
Public statements of ANKER-TEC or its agents, in particular in advertisements or in the marking, do not constitute descriptions of the quality of the goods or a guarantee.
The Customer is aware that the state of the art cannot exclude defects in the software. If operational and maintenance instructions of ANKER-TEC are not complied with, or if product modifications are carried out, parts exchanged, or consumables used which do not comply with the original specifications, the Customer has no claims against ANKER-TEC for defects resulting therefrom. If ANKER-TEC substantiates that a certain defect is due to such a factor, the Customer then only has a claim against ANKER-TEC if said allegation is disproved.
If the items delivered exhibit defects for which ANKER-TEC is responsible, ANKER-TEC is only obliged to remove the defect. ANKER-TEC is entitled to regularly perform up to 3 rectifications. If the rectification fails for good, the Customer may either reduce the purchase price or rescind the agreement.
The Customer has no right to self-performance.
Claims of the Customer based on a defect in items delivered become time-barred after 1 year.
The limitation period commences upon delivery.
Further-reaching claims of the Customer are excluded with the exception of the claims under Clause of these Terms.
ANKER-TEC is only liable for damages if liability is mandatory under the applicable law, e.g. under the German Product Liability Act [Produkthaftungsgesetz] and in the event of injury to life, limb or health, or if ANKER-TEC breaches a guarantee, or if ANKER-TEC has fraudulently concealed a defect, or if the damage is caused by grossly negligent behaviour of organs or senior executives of ANKER-TEC; or if the damage is based on intentional conduct, or if ANKER-TEC culpably breaches a material contractual obligation.
In all other cases the liability of ANKER-TEC for damages is excluded, irrespective of the legal basis.
In any case, liability is limited to the damage typical for the respective type of contract which ANKER-TEC, on the date of conclusion of the Contract, reasonably could foresee or should have been able to foresee on the basis of the circumstances and facts available to it. Such limitation of liability shall not apply if a limitation of liability is excluded by law, e.g. in the event of liability under the German Product Liability Act and in the event of injury to life, limb or health; neither shall the limitation of liability apply if ANKER-TEC breaches a guarantee it assumed or if the damage is based on gross negligence, intentional or malicious conduct.
The exclusion of liability and the limitation of liability in line with the foregoing paragraphs applies also with regard to the personal liability of the employees and vicarious agents of ANKER-TEC.
Liability for reimbursement of expenses does also apply only according to the foregoing.
ANKER-TEC is only liable for the restoration of data if the destruction of the same was caused by gross negligence of organs or a senior executive of ANKER-TEC, or if it was caused by intent, or if protection of the data was a material contractual obligation of ANKER-TEC. The Customer must ensure by appropriate state-of-the-art security measures that such data can be restored with reasonable effort.
The Customer undertakes to act as a reference for other customers of ANKER-TEC. In particular, ANKER-TEC is entitled to take photographs and make film recordings of the Customer‘s equipment and to exploit them without remuneration. ANKER-TEC is entitled to name the Customer and the specification of the equipment at the Customer’s premises as a reference in advertisements and may also exploit photographs and films of the Customer’s equipment without additional remuneration. ANKER-TEC shall inform the Customer of his being used as a reference and the Customer is entitled to oppose his being used as a reference if he has a justified interest.
ANKER-TEC and the Customer mutually undertake to treat all business and trade secrets of the other party for an indefinite period as confidential, not to make them available to third parties or to use them in any way. The documents, drawings and other information, which the other party receives as part of the business relationship, may only be used within the scope of the relevant contractual purpose. If there are particular secrecy interests on the part of ANKER-TEC and/or the Customer, both Parties shall sign a non-disclosure agreement stipulating the extent of the duty of confidentiality and contractual penalties for any breaches of duty.
Without the prior consent of ANKER-TEC, the Customer is not entitled to assign to third parties any rights or claims under this Agreement nor to assign to third parties this Agreement as a whole. The Customer is entitled to effect set-off and/or retention-rights only with respect to counterclaims which are uncontested, res judicata, or acknowledged by ANKER-TEC.
The exclusive place of jurisdiction for all disputes between the Customer and ANKER-TEC is the District Court of Korbach shall thus have jurisdiction for claims falling under the jurisdiction of the district courts (Landgerichte). This venue clause also applies if the Customer has his place of domicile or registered office. The laws of the Federal Republic of Germany apply exclusively to the exclusion of the conflicts of law provisions. The United Nations Convention on Contracts for the International Sale of Goods (CISG) does not.
© ANKER-TEC GmbH